Please read these Terms and Conditions (“Terms”, “Terms and Conditions”) carefully before using the websitting.co.uk website (the “Website”) and the web design and related services (collectively, the “Services”) offered by Websitting.co.uk (“us”, “we”, or “our”).

Your access to and use of the Services is conditioned upon your acceptance of and compliance with these Terms. These Terms apply to all visitors, users, and others who wish to access or use the Services. By accessing or using the Services, you agree to be bound by these Terms. If you disagree with any part of the terms, then you do not have permission to access the Services.

1. Definitions

• “Agreement”: Refers to these Terms and Conditions, along with any Quotation, Scope of Work, or other contractual documents exchanged and agreed upon between Websitting.co.uk and the Client.
• “Client”: The individual, company, or entity purchasing Services from Websitting.co.uk.
• “Website”: Refers to the website developed or being developed by Websitting.co.uk for the Client, as detailed in the Quotation.
• “Services”: Includes, but is not limited to, web design, web development, website maintenance, hosting assistance, graphic design, content creation/management, SEO services, and consultation provided by Websitting.co.uk.
• “Quotation”: The document provided by Websitting.co.uk to the Client detailing the Services to be provided and the associated fees.
• “Project”: The specific web design and/or development work undertaken for the Client as outlined in the Quotation.
• “Content”: All text, images, videos, graphics, data, and other materials provided by the Client or by Websitting.co.uk for inclusion in the Website.
• “Intellectual Property Rights”: Patents, rights to inventions, copyright and related rights, moral rights, trade marks, business names and domain names, rights in get-up, goodwill and the right to sue for passing off, rights in designs, rights in computer software, database rights, rights to use, and protect the confidentiality of, confidential information (including know-how and trade secrets) and all other intellectual property rights, in each case whether registered or unregistered and including all applications and rights to apply for and be granted, renewals or extensions of, and rights to claim priority from, such rights and all similar or equivalent rights or forms of protection which subsist or will subsist now or in the future in any part of the world.
• “CMS”: Content Management System.
• “SEO”: Search Engine Optimisation.
• “Business Day”: A day other than a Saturday, Sunday or public holiday in England when banks in London are open for business.

2. Services Offered

2.1. Websitting.co.uk provides a range of web design and development services, including but not limited to: * Custom website design and development. * Responsive web design (mobile-friendly). * E-commerce website development. * Content Management System (CMS) integration and customisation (e.g., WordPress). * Website redesigns and updates. * Basic Search Engine Optimisation (SEO) setup. * Website maintenance and support packages (as separately agreed). * Graphic design services related to the website project.

2.2. The specific Services to be provided for each Project will be detailed in a written Quotation. Any services not explicitly listed in the Quotation are considered outside the scope of the Project and may incur additional charges if requested by the Client.

3. Quotations, Orders, and Agreement

3.1. All Quotations provided by Websitting.co.uk are valid for a period of thirty (30) days from the date of issue, unless otherwise stated. 3.2. To accept a Quotation and initiate a Project, the Client must provide written confirmation (email is acceptable) and pay any required deposit as specified in the Quotation. 3.3. Upon acceptance of the Quotation and payment of the deposit, a binding Agreement is formed between the Client and Websitting.co.uk, governed by these Terms and Conditions and the specifics of the Quotation. 3.4. Any requests for changes or additions to the scope of work after the Agreement is formed must be submitted in writing and may be subject to additional fees and adjustments to the project timeline. Websitting.co.uk will provide a revised Quotation or addendum for such changes.

4. Fees and Payment Terms

4.1. The Client agrees to pay the fees for the Services as set out in the Quotation. 4.2. Deposit: A non-refundable deposit (typically 50% of the total project fee, unless otherwise specified in the Quotation) is required before any work commences. 4.3. Interim Payments: For larger projects, interim payments may be scheduled at specific milestones, as detailed in the Quotation. 4.4. Final Payment: The remaining balance is due upon completion of the Project, prior to the Website going live or final files being delivered. 4.5. All payments must be made in Pounds Sterling (GBP) within fourteen (14) days of the invoice date, unless otherwise agreed in writing. 4.6. Payments can be made via bank transfer or other methods as agreed with Websitting.co.uk. 4.7. Late Payments: If any invoiced amount is not received by Websitting.co.uk by the due date, then without prejudice to any other rights or remedies: (a) Websitting.co.uk may charge interest on such overdue sum from the due date until payment of the overdue sum, whether before or after judgment. Interest under this clause will accrue each day at 4% a year above the Bank of England’s base rate from time to time, but at 4% a year for any period when that base rate is below 0%. (b) Websitting.co.uk may suspend provision of Services (including taking the Website offline) until payment has been made in full. 4.8. All fees quoted are exclusive of Value Added Tax (VAT) unless otherwise stated. If VAT is applicable, it will be added to the invoice at the prevailing rate. 4.9. Any third-party costs, such as premium themes, plugins, stock photography, or domain name registration and hosting fees, are not included in our standard Quotation unless explicitly stated and will be billed separately or are the responsibility of the Client.

5. Client Obligations and Responsibilities

5.1. The Client agrees to provide Websitting.co.uk with all necessary information, Content (text, images, logos, etc.), and materials required for the completion of the Project in a timely manner and in the requested format. 5.2. The Client warrants that all Content provided to Websitting.co.uk is either owned by the Client or that the Client has full permission and rights to use such Content. The Client agrees to indemnify and hold harmless Websitting.co.uk from any claims arising from the use of Content supplied by the Client. 5.3. The Client is responsible for proofreading all Content before and after it is published on the Website. 5.4. The Client agrees to provide timely feedback and approvals throughout the design and development process. Delays in providing necessary information, Content, or feedback may result in extensions to the project timeline and may incur additional costs. 5.5. If the Client wishes to arrange their own website hosting and domain name registration, they must provide Websitting.co.uk with full access details (e.g., FTP, cPanel, database credentials) required to upload and configure the Website. Websitting.co.uk is not responsible for issues arising from the Client’s chosen hosting provider if not recommended or managed by us.

6. Project Timelines and Delays

6.1. Websitting.co.uk will provide an estimated timeline for the completion of the Project. This timeline is an estimate and is not contractually binding unless explicitly stated as such in the Quotation. 6.2. The project timeline commences upon receipt of the signed Agreement/Quotation acceptance and the initial deposit. 6.3. Websitting.co.uk will use reasonable endeavours to meet the estimated project timeline. However, we shall not be liable for any delays caused by factors beyond our reasonable control, including but not limited to: (a) Delays in the Client providing necessary Content, information, or feedback. (b) Scope changes requested by the Client. (c) Issues with third-party services or providers. 6.4. If the Project is significantly delayed due to the Client’s failure to meet their obligations (e.g., providing content or feedback) for a period exceeding thirty (30) days beyond the agreed deadline for such input, Websitting.co.uk reserves the right to: (a) Pause the Project and reschedule its completion, which may affect the overall delivery date. (b) Invoice for work completed to date. (c) In cases of prolonged inactivity (e.g., 60 days or more without communication or provision of required materials despite reasonable attempts by Websitting.co.uk to make contact), Websitting.co.uk may deem the project abandoned and terminate the Agreement. In such cases, the deposit and any interim payments will be non-refundable.

7. Design Process, Revisions, and Acceptance

7.1. Design Mock-ups: Where applicable, Websitting.co.uk will provide the Client with design mock-ups for review and approval. 7.2. Revisions: The Quotation will typically include a set number of revision rounds for the design phase (e.g., two or three rounds). A revision round consists of a consolidated list of changes requested by the Client. 7.3. Additional revisions beyond those specified in the Quotation, or significant changes to already approved designs, may be subject to additional charges at our standard hourly rate. We will inform the Client if a request is considered outside the scope of included revisions. 7.4. Development: Once the design is approved, Websitting.co.uk will proceed with the development and build of the Website. Significant design changes requested after development has commenced may incur substantial additional costs and timeline adjustments. 7.5. Testing: Websitting.co.uk will test the Website for functionality and compatibility with modern, up-to-date versions of major web browsers (e.g., Chrome, Firefox, Safari, Edge). We do not guarantee compatibility with outdated or obscure browser versions. 7.6. Client Review and Acceptance: Upon completion of the development and initial testing, the Website will be made available to the Client for review and testing on a staging server or directly if agreed. 7.7. The Client will have a specified period (e.g., seven to fourteen (7-14) Business Days, as stated in the Quotation or project plan) to review the Website and provide a single, consolidated list of any bugs, errors, or omissions. 7.8. Websitting.co.uk will rectify any reported bugs or errors covered under the original scope of work at no additional cost. 7.9. Final Acceptance (Sign-off): The Project is considered complete and accepted (“Sign-off”) upon the earliest of the following: (a) Written confirmation (email acceptable) from the Client that the Website is satisfactory. (b) The Client begins using the Website for its intended purpose (e.g., public launch, processing orders). (c) The Client does not provide feedback or report issues within the specified review period after being notified of the Website’s readiness for final review. 7.10. Once Sign-off has occurred, any further work, changes, or additions will be considered new work and will be chargeable at our standard rates or under a separate maintenance agreement.

8. Content and Copyright

8.1. Client Content: The Client is solely responsible for obtaining all necessary permissions, licences, and consents for any Content provided to Websitting.co.uk for inclusion in the Website. This includes, but is not limited to, text, images, logos, trademarks, and video/audio files. The Client indemnifies Websitting.co.uk against any claims, damages, or costs arising from the use of such Content. 8.2. Our Content: Content created by Websitting.co.uk specifically for the Project (e.g., custom graphics, written copy if included in the scope) will become the property of the Client upon full and final payment for the Project, unless otherwise agreed in writing. 8.3. Websitting.co.uk reserves the right to use stock images, fonts, or other third-party assets. The licences for these assets may have specific terms of use, and the Client agrees to abide by them. Costs for premium stock assets are typically not included unless specified in the Quotation. 8.4. Websitting.co.uk reserves the right to refuse to handle any Content that we deem to be unlawful, offensive, defamatory, or otherwise inappropriate.

9. Intellectual Property Rights

9.1. Client Ownership: Upon full and final payment of all outstanding fees, the Client will own the Intellectual Property Rights to the final, assembled Website design and any custom code or Content specifically created by Websitting.co.uk for the Client as part of the Project. 9.2. Websitting.co.uk’s Retained Rights: Websitting.co.uk retains: (a) Ownership of all original source files, working files, and any pre-existing code, tools, libraries, CMS platforms (e.g., WordPress core), plugins, themes, or proprietary techniques used in the creation of the Website (“Background IP”). The Client is granted a non-exclusive, worldwide, royalty-free licence to use such Background IP to the extent necessary for the operation of the Website. (b) The right to reuse elements of code, design, or know-how from the Project for future projects, provided it does not infringe on the Client’s specific branding or confidential information. (c) The right to display the completed Project in our portfolio, website, and other marketing materials, including a discreet credit link or statement (e.g., “Website designed by Websitting.co.uk”) in the footer of the Client’s Website, unless otherwise agreed in writing (which may incur an additional fee). 9.3. Third-Party Software/Assets: Any third-party software, themes, plugins, or assets used in the Project will be subject to their own respective licences, and the Client agrees to comply with such terms. Websitting.co.uk will inform the Client of any significant third-party licences.

10. Website Hosting and Domain Names

10.1. Unless explicitly included as part of a specific hosting and maintenance package in the Quotation, Websitting.co.uk does not provide ongoing website hosting or domain name registration services as standard. 10.2. The Client is responsible for arranging and paying for their own website hosting and domain name registration. 10.3. If requested, Websitting.co.uk can offer recommendations for hosting providers or assist with the setup on the Client’s chosen hosting, which may be a chargeable service. 10.4. If the Client’s chosen hosting environment is inadequate or causes issues with the Website’s performance or functionality, Websitting.co.uk is not responsible for rectifying such issues without additional charge. 10.5. Where Websitting.co.uk arranges hosting or domain registration on behalf of the Client, these services will be subject to the terms and conditions of the third-party provider, and renewal fees will be the responsibility of the Client unless part of an ongoing management package with Websitting.co.uk.

11. Support and Maintenance

11.1. Upon launch of the Website, Websitting.co.uk will provide a warranty period of thirty (30) days to rectify any bugs or errors (i.e., the Website not functioning as per the agreed scope) at no additional cost. This warranty does not cover issues caused by: (a) Modifications made to the Website by the Client or any third party. (b) Malfunctions of third-party software, plugins, or hosting. (c) Changes in browser or operating system compatibility after the warranty period. (d) User error or misuse of the Website or CMS. 11.2. Any requests for support or changes outside of this initial 30-day warranty period, or for tasks not covered by the warranty (e.g., new features, content updates performed by us), will be chargeable at our standard hourly rate or as part of a separate Website Maintenance Agreement. 11.3. Websitting.co.uk offers optional ongoing Website Maintenance Packages, which will be detailed in a separate agreement and typically cover services like software updates, security monitoring, backups, and a set amount of support time.

12. Warranties and Disclaimers

12.1. Websitting.co.uk warrants that the Services will be provided with reasonable care and skill, in accordance with generally accepted industry standards. 12.2. Websitting.co.uk warrants that the completed website will, for a period of thirty (30) days from launch, function substantially in accordance with the agreed specifications detailed in the Quotation, provided it is used on a supported hosting environment. 12.3. Disclaimer: Except as expressly stated in this Agreement, Websitting.co.uk provides the Services and the Website on an “as is” basis. To the fullest extent permitted by law, all other warranties, conditions, or terms, whether express or implied (by statute, common law or otherwise), including but not limited to implied warranties of merchantability, fitness for a particular purpose, or non-infringement, are excluded. 12.4. Websitting.co.uk does not warrant that: (a) The Website will be uninterrupted or error-free. (b) The Website will be compatible with all future browser versions or devices. (c) The Website will achieve any specific ranking in search engines (unless specific SEO services with guarantees are agreed in a separate contract). (d) The Website will be secure from all forms of malicious attack (though we will implement reasonable security measures). 12.5. Websitting.co.uk is not responsible for the performance or any issues arising from third-party services, plugins, themes, or APIs integrated into the Website. While we will endeavour to select reliable third-party components, their ongoing functionality and compatibility are outside our direct control.

13. Limitation of Liability

13.1. Nothing in this Agreement shall limit or exclude Websitting.co.uk’s liability for: (a) Death or personal injury caused by its negligence. (b) Fraud or fraudulent misrepresentation. (c) Any other liability which cannot be limited or excluded by applicable law. 13.2. Subject to clause 13.1, Websitting.co.uk’s total aggregate liability to the Client, whether in contract, tort (including negligence), breach of statutory duty, or otherwise, arising under or in connection with this Agreement shall be limited to the total fees paid by the Client to Websitting.co.uk under the specific Project Quotation to which the claim relates. 13.3. Websitting.co.uk shall not be liable to the Client for any: (a) Loss of profits. (b) Loss of sales or business. (c) Loss of agreements or contracts. (d) Loss of anticipated savings. (e) Loss of use or corruption of software, data, or information. (f) Loss of or damage to goodwill. (g) Indirect or consequential loss. 13.4. This clause 13 shall survive termination of the Agreement.

14. Termination

14.1. This Agreement may be terminated by either party with immediate effect by giving written notice to the other party if: (a) The other party commits a material breach of any term of this Agreement and (if such breach is remediable) fails to remedy that breach within fourteen (14) days of being notified in writing to do so. (b) The other party suspends, or threatens to suspend, payment of its debts or is unable to pay its debts as they fall due or admits inability to pay its debts or is deemed unable to pay its debts within the meaning of section 123 of the Insolvency Act 1986. (c) The other party commences negotiations with all or any class of its creditors with a view to rescheduling any of its debts, or makes a proposal for or enters into any compromise or arrangement with its creditors. (d) A petition is filed, a notice is given, a resolution is passed, or an order is made, for or in connection with the winding up of that other party (being a company). 14.2. Websitting.co.uk may terminate this Agreement with immediate effect by written notice if the Client fails to pay any amount due under this Agreement on the due date for payment and remains in default not less than seven (7) days after being notified in writing to make such payment. 14.3. The Client may terminate this Agreement at any time by providing written notice to Websitting.co.uk. In such an event: (a) The initial deposit will be non-refundable. (b) The Client will be liable to pay Websitting.co.uk for all work carried out up to the date of termination, calculated at our standard hourly rate or as a proportion of the project milestones achieved, whichever is greater, plus any unavoidable third-party costs incurred. 14.4. Consequences of Termination: (a) Upon termination, the Client shall immediately pay all of Websitting.co.uk’s outstanding unpaid invoices and interest and, in respect of Services supplied but for which no invoice has been submitted, Websitting.co.uk may submit an invoice, which shall be payable immediately on receipt. (b) Websitting.co.uk will deliver to the Client any completed work for which payment has been received in full. No work will be released for which payment has not been made. (c) Any provision of this Agreement that expressly or by implication is intended to come into or continue in force on or after termination shall remain in full force and effect.

15. Confidentiality

15.1. Each party agrees to keep confidential all information concerning the business, affairs, customers, clients, or suppliers of the other party (“Confidential Information”) which it may obtain in connection with this Agreement. 15.2. Each party may disclose Confidential Information: (a) To its employees, officers, representatives, or advisers who need to know such information for the purposes of carrying out the party’s obligations under this Agreement. Each party shall ensure that its employees, officers, representatives, or advisers to whom it discloses the other party’s confidential information comply with this clause 15. (b) As may be required by law, a court of competent jurisdiction or any governmental or regulatory authority. 15.3. This clause 15 shall survive termination of the Agreement.

16. Data Protection

16.1. Both parties will comply with all applicable requirements of the Data Protection Act 2018 and the UK General Data Protection Regulation (UK GDPR) (collectively, “Data Protection Legislation”). This clause 16 is in addition to, and does not relieve, remove or replace, a party’s obligations or rights under the Data Protection Legislation. 16.2. To the extent that Websitting.co.uk processes any Personal Data on behalf of the Client in providing the Services, Websitting.co.uk shall: (a) Process that Personal Data only on the written instructions of the Client unless Websitting.co.uk is required by law to otherwise process that Personal Data. (b) Ensure that it has in place appropriate technical and organisational measures to protect against unauthorised or unlawful processing of Personal Data and against accidental loss or destruction of, or damage to, Personal Data. (c) Ensure that all personnel who have access to and/or process Personal Data are obliged to keep the Personal Data confidential. (d) Not transfer any Personal Data outside the UK or European Economic Area unless the prior written consent of the Client has been obtained and appropriate safeguards are in place. (e) Assist the Client, at the Client’s cost, in responding to any request from a Data Subject and in ensuring compliance with its obligations under the Data Protection Legislation with respect to security, breach notifications, impact assessments and consultations with supervisory authorities or regulators. (f) Notify the Client without undue delay on becoming aware of a Personal Data breach. (g) At the written direction of the Client, delete or return Personal Data and copies thereof to the Client on termination of the agreement unless required by law to store the Personal Data. (h) Maintain complete and accurate records and information to demonstrate its compliance with this clause 16. 16.3. The Client consents to Websitting.co.uk appointing third-party processors of Personal Data under this agreement (e.g., hosting providers, plugin developers) provided that Websitting.co.uk enters into a written agreement with the third-party processor incorporating terms which are substantially similar to those set out in this clause 16.

17. Force Majeure

17.1. Neither party shall be in breach of this Agreement nor liable for delay in performing, or failure to perform, any of its obligations under this Agreement if such delay or failure results from events, circumstances or causes beyond its reasonable control (“Force Majeure Event”). Such events include, but are not limited to, acts of God, flood, fire, earthquake, explosion, governmental actions, war, invasion or hostilities, terrorist threats or acts, riot or other civil unrest, national emergency, revolution, insurrection, epidemic or pandemic, lockouts, strikes or other labour disputes (whether or not relating to our workforce), or restraints or delays affecting carriers or inability or delay in obtaining supplies of adequate or suitable materials, or telecommunication breakdown or power outage. 17.2. If a Force Majeure Event prevents, hinders or delays the affected party’s performance of its obligations for a continuous period of more than thirty (30) days, the party not affected by the Force Majeure Event may terminate this Agreement by giving fourteen (14) days’ written notice to the affected party.

18. Notices

18.1. Any notice or other communication given to a party under or in connection with this Agreement shall be in writing and shall be: (a) Delivered by hand or by pre-paid first-class post or other next working day delivery service at its registered office (if a company) or its principal place of business (in any other case); or (b) Sent by email to the address specified in the Quotation or as otherwise notified in writing by each party. 18.2. Any notice or communication shall be deemed to have been received: (a) If delivered by hand, on signature of a delivery receipt or at the time the notice is left at the proper address. (b) If sent by pre-paid first-class post or other next working day delivery service, at 9.00 am on the second Business Day after posting or at the time recorded by the delivery service. (c) If sent by email, at the time of transmission, or, if this time falls outside business hours in the place of receipt, when business hours resume. In this clause 18.2(c), business hours means 9.00am to 5.00pm Monday to Friday on a day that is not a public holiday in the place of receipt. 18.3. This clause does not apply to the service of any proceedings or other documents in any legal action or, where applicable, any arbitration or other method of dispute resolution.

19. Assignment and Other Dealings

19.1. Websitting.co.uk may at any time assign, mortgage, charge, subcontract, delegate, declare a trust over or deal in any other manner with any or all of its rights and obligations under this Agreement. We will notify the Client if we subcontract any significant part of the Services. 19.2. The Client shall not assign, transfer, mortgage, charge, subcontract, delegate, declare a trust over or deal in any other manner with any of its rights and obligations under this Agreement without the prior written consent of Websitting.co.uk.

20. Entire Agreement

20.1. This Agreement (comprising these Terms and Conditions and the accepted Quotation) constitutes the entire agreement between the parties and supersedes and extinguishes all previous agreements, promises, assurances, warranties, representations, and understandings between them, whether written or oral, relating to its subject matter. 20.2. Each party acknowledges that in entering into this Agreement it does not rely on, and shall have no remedies in respect of, any statement, representation, assurance, or warranty (whether made innocently or negligently) that is not set out in this Agreement.

21. Severability

21.1. If any provision or part-provision of this Agreement is or becomes invalid, illegal, or unenforceable, it shall be deemed deleted, but that shall not affect the validity and enforceability of the rest of this Agreement. 21.2. If any provision or part-provision of this Agreement is deemed deleted under clause 21.1, the parties shall negotiate in good faith to agree a replacement provision that, to the greatest extent possible, achieves the intended commercial result of the original provision.

22. Waiver

22.1. A waiver of any right or remedy under this Agreement or by law is only effective if given in writing and shall not be deemed a waiver of any subsequent right or remedy. 22.2. A failure or delay by a party to exercise any right or remedy provided under this Agreement or by law shall not constitute a waiver of that or any other right or remedy, nor shall it prevent or restrict any further exercise of that or any other right or remedy. No single or partial exercise of any right or remedy provided under this Agreement or by law shall prevent or restrict the further exercise of that or any other right or remedy.

23. No Partnership or Agency

23.1. Nothing in this Agreement is intended to, or shall be deemed to, establish any partnership or joint venture between the parties, constitute either party the agent of the other, or authorise either party to make or enter into any commitments for or on behalf of the other party.

24. Third Party Rights

24.1. Unless it expressly states otherwise, this Agreement does not give rise to any rights under the Contracts (Rights of Third Parties) Act 1999 to enforce any term of this Agreement.

25. Governing Law and Jurisdiction

25.1. This Agreement, and any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with it or its subject matter or formation, shall be governed by and construed in accordance with the law of England and Wales. 25.2. Each party irrevocably agrees that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with this Agreement or its subject matter or formation.

26. Dispute Resolution

26.1. If a dispute arises out of or in connection with this Agreement or the performance, validity or enforceability of it (“Dispute”) then the parties shall follow the procedure set out in this clause: (a) Either party shall give to the other written notice of the Dispute, setting out its nature and full particulars (“Dispute Notice”), together with relevant supporting documents. On service of the Dispute Notice, the [Owner/Manager of Websitting.co.uk] and the [Client’s main contact or representative] shall attempt in good faith to resolve the Dispute. (b) If the [Owner/Manager of Websitting.co.uk] and the [Client’s main contact or representative] are for any reason unable to resolve the Dispute within thirty (30) days of service of the Dispute Notice, the parties will attempt to settle it by mediation in accordance with the CEDR (Centre for Effective Dispute Resolution) Model Mediation Procedure. Unless otherwise agreed between the parties, the mediator will be nominated by CEDR. To initiate the mediation, a party must serve notice in writing (“ADR notice”) to the other party to the Dispute, referring the dispute to mediation. A copy of the ADR notice should be sent to CEDR. 26.2. No party may commence any court proceedings in relation to the whole or part of the Dispute until thirty (30) days after service of the ADR notice, provided that the right to issue proceedings is not prejudiced by a delay. 26.3. If the Dispute is not resolved within sixty (60) days after service of the ADR notice, or either party fails to participate or ceases to participate in the mediation before the expiry of that period, or the mediation terminates before the expiry of that period, the Dispute shall be finally resolved by the courts of England and Wales in accordance with Clause 25 (Governing Law and Jurisdiction).

27. Changes to Terms and Conditions

27.1. Websitting.co.uk reserves the right, at our sole discretion, to modify or replace these Terms at any time. If a revision is material, we will provide at least thirty (30) days’ notice prior to any new terms taking effect. What constitutes a material change will be determined at our sole discretion. 27.2. By continuing to access or use our Services after any revisions become effective, you agree to be bound by the revised terms. If you do not agree to the new terms, you are no longer authorized to use the Services. 27.3. For existing Clients with active Projects, the Terms in place at the time of their Project Agreement will apply to that Project, unless mutually agreed otherwise. New terms will apply to any future Projects or new service agreements.

Acceptance by Client:

By commissioning Websitting.co.uk for services, the Client acknowledges that they have read, understood, and agree to be bound by these Terms and Conditions.